Welcome to PCO Blogs

This is a place for Registered Users to share their technical view and opinions in form of blogs which they think might be useful to the greater PCO community. We invite prolific writers to share their insights and witticisms, but remind all contributors to be mindful of any copyright rules. ProjectControlsOnline will not be held responsible for any breach in rights and responsible users will be held accounted for the same.

Please note that you may NOT get badges, stars etc. by posting blogs here as they are pretty meaningless as they do NOT make you wealthier, fitter or more attractive to the opposite sex! The best you will get from contributing here is the satisfaction/self-respect from knowing you have helped others.  So, please continue to make positive contribution to this community portal and extend whatever help you can to your fellow colleagues.  Thanks!

 

Please read this help page before creating a blog

spacer
Latest blog entries

IMPLIED OBLIGATIONS AND TIMELY CONTRACT TIME EXTENSIONS & CHANGE ORDERS

May 19

Written by:
19 May 2011 17:26  RssIcon

The verbiage within a typical construction contract specifies the scope of work and the rights and obligations of the stakeholders. The contract documents provide “expressed” provisions within the contracts explicit verbiage, plans and specifications to which the parties agree. However, there are also “implied” obligations which arise from the courts, their applicable system of law and “common practice” which must also be considered.

Implied obligations include;  

·         A duty to schedule the work activity

·         A duty to coordinate work activity

·         A duty not to adversely hinder and interfere with work progress

·         A duty to cooperate with stakeholders

·         A duty to mitigate delay and minimize impact

·         A duty to grant reasonable time extensions in an expeditious manner

Quite often, once an Owner has put together the contract “package” and released the contract documents for hard bid or negotiated a contract with a Contractor which includes project duration, perhaps milestones and a liquidated damages clause, the Owner considers his part of the scheduling equation complete. Many Owners stoically take the position that the contract completion date is an absolute, regardless of changes to scope, disruption and delay, force majeure (acts of God) and any other factor which might affect adversely the contract completion date. There are multitudes of variations of “no damages for delay” exculpatory language which is intended to thwart any claim for delay damages, excusable or not.

A large portion of construction contracts, particularly government contracts” include “force majeure” language which allows for excusable delay without compensation due to such factors as:

·         Atypical Severe Weather Delay

·         Earthquakes

·         Epidemics

·         Embargos

·         Fires

·         Floods

·         Quarantine

·         Riots, Insurrections and Acts of War

The ability of the contractor to perform can also be impacted by changes to scope, events and non-events which the contractor could not have reasonably anticipated which cannot be mitigated by reasonable measures to eliminate or minimize impact and cost. Regardless of their source or nature, delay impacts virtually all parties to the contract. Both the contractor and the owner will experience cost increase in extended overhead, materials escalation and other prolongation cost should the contract take longer to complete than planned.

Consequently, all parties to the contract have an implied, even if not explicitly stated, obligation to minimize the detrimental impact of delay to the progress of work activity. This obligation is not just limited to the contract end date. It arises with the Notice to Proceed and the start of construction and continues through each schedule update to the completion of the project.

Delays within a project inevitably fall into one of two categories, compensable and non-compensable. The standard of measure of delay is not limited solely to the contract completion date. Interim delay can and does occur which when mitigated incurs an associated cost. Many Owners ignore this simple fact when faced with interim delay and forced to consider whether to grant a timely time extension and/or maintain the original contract completion date.

Whether loss arises from excusable Acts of God or Owner caused delay, the cause and effect relationship associated with excusable interim delay creates a basis of entitlement for equitable adjustment in the event commensurate time is not granted the contractor. When facing such interim delay and impact, the Owner has an obligation to weigh and decide upon the least costly means of minimizing cost. Simply ignoring the problem is a choice which has its own implications. Such choices typically worsen cost and delay impact, exposing the Owner to liability for the consequence of "forced" or “constructive” acceleration.  This can be true even if the project finishes by the planned completion date.

Delaying a decision to grant an excusable time extension in no different than ignoring it. With the passing of time, the opportunity for choice diminishes and the likelihood of receiving a claim for impact and delay increases. The longer it takes to grant a time extension, the less the time extension means to the contractor and consequential cost.

The issue of scheduling and coordination is not simply limited to timely contract extensions. The duty to of all parties to participate in the scheduling and coordination of a project extends to the review and approval of the project CPM baseline schedule as well as monitoring project CPM updates and assessing a “Time Impact Analysis” for changes, events and nonevents occurring over the course of the project.

As with the majority of submittals, the Owner has a duty to review and critique the contract CPM baseline schedule. This review extends to such issues and items as;

  • ·         Is the Critical Path Reasonable?
  • ·         Are key resources clearly defined and properly allocated?
  • ·         Are there unreasonable constraints, open ended logic, negative lags, and other poor    scheduling practices included in the CPM schedule model?
  • ·         Are the work activities clearly associated with the various defined work areas?
  • ·         Are soft logic ties between areas of work defined and/or obvious?
  • ·         Is the schedule complete with no open logic ends or predecessors other than NTP and Completion?
  • ·         Does the CPM schedule show an early completion date?

The time tested attitude of waiting till the end of the project to work everything out is fraught with frustration, disputes and expensive litigation. Any Owner who has settled a significant claim or received a large adverse award against it will likely attest to the importance of these items. If not, they are likely to repeat the process again and again until they do.

Copyright ©2011 Mark G Cundiff, PSP

73 comment(s) so far...


Gravatar

re:

I like your post a lot! You should write some more on this!Great job coming with such terrific post!


alchemist
www.inspgift.com

By alchemist on   29 October 2013 20:03
Gravatar

Re: IMPLIED OBLIGATIONS AND TIMELY CONTRACT TIME EXTENSIONS & CHANGE ORDERS

Thanks for all your information, Website is very nice and informative content.
Packers and Movers in Noida @
www.expert5th.in/packers-and-movers-noida/
Packers and Movers in Thane @
www.expert5th.in/packers-and-movers-thane/
Packers and Movers in Navi Mumbai @
www.expert5th.in/packers-and-movers-navimumbai/
Packers and Movers in Ghaziabad @
www.expert5th.in/packers-and-movers-ghaziabad/
Packers and Movers in Faridabad @
www.expert5th.in/packers-and-movers-faridabad/
Packers and Movers Amritsar OR
www.expert5th.in/packers-and-movers-amritsar/
Packers and Movers Jalandhar OR
www.expert5th.in/packers-and-movers-jalandhar/

By Packers and Movers in Navi Mumbai on   22 April 2015 02:37
Gravatar

Re: IMPLIED OBLIGATIONS AND TIMELY CONTRACT TIME EXTENSIONS & CHANGE ORDERS

Packers and Movers India

By Packers and Movers Navi Mumbai on   22 April 2015 02:38
Gravatar

Re: IMPLIED OBLIGATIONS AND TIMELY CONTRACT TIME EXTENSIONS & CHANGE ORDERS

Thanks for post this helpful post - Please visit for More information about -
Packers and Movers in Hyderabad
Packers and Movers in Pune
Packers and Movers in Mumbai

By Packers and Movers India on   22 April 2015 02:39
Gravatar

Re: IMPLIED OBLIGATIONS AND TIMELY CONTRACT TIME EXTENSIONS & CHANGE ORDERS

Thanks for post this helpful post - Please visit for More information about -
Packers and Movers in Chennai
Packers and Movers in Delhi
Packers and Movers in Bangalore
Packers and Movers in Gurgaon

By Packers and Movers India on   22 April 2015 02:39
Gravatar

Re: IMPLIED OBLIGATIONS AND TIMELY CONTRACT TIME EXTENSIONS & CHANGE ORDERS

Thanks for Nice and Informative Post. This article is really contains lot more information about This Topic. -
Packers and Movers Hyderabad
Packers and Movers Bangalore
Packers and Movers Delhi
Packers and Movers Noida
Packers and Movers Chennai
Packers and Movers Pune
Packers and Movers Mumbai
Packers and Movers Gurgaon

By Packers and Movers India on   22 April 2015 02:40
Gravatar

Packers and Movers India

Thanks for sharing. I hope it will be helpful for too many people that are searching for this topic.
Packers and Movers Pune
Packers and Movers in Pune

By Packers and Movers Pune on   18 June 2015 05:57
Gravatar

Packers and Movers India

Thanks for sharing. I hope it will be helpful for too many people that are searching for this topic.
Packers and Movers Pune

By Akash Singh on   03 July 2015 03:43
Gravatar

Packers and Movers India


Thanks for sharing. I hope it will be helpful for too many people that are searching for this topic.
Movers and Packers Hyderabad
Movers and Packers Bangalore
Movers and Packers Pune

By Akash Singh on   03 July 2015 03:44
Gravatar

Packers and Movers India

Thanks for sharing. I hope it will be helpful for too many people that are searching for this topic.
Movers and Packers Delhi
Movers and Packers Gurgaon
Movers and Packers Mumbai

By Akash Singh on   03 July 2015 03:45
Gravatar

Packers and Movers India

Thanks for sharing. I hope it will be helpful for too many people that are searching for this topic.
Pune Packers and Movers

By Akash Singh on   03 July 2015 03:45
Gravatar

Packers & Movers

The article is fantastic.I enjoyed alot while reading. Thanks for sharing a valubale information with us.
movers and packers in delhi @ ezmove.in/packers-and-movers-delhi.html
packers and movers in navi mumbai @ ezmove.in/packers-and-movers-mumbai.html
movers and packers in mumbai @ ezmove.in/packers-and-movers-mumbai.html
movers and packers in pune @ ezmove.in/packers-and-movers-pune.html
movers and packers in hyderabad @ ezmove.in/packers-and-movers-hyderabad.html
packers and movers in bangalore @ ezmove.in/packers-and-movers-bangalore.html
chennai packers and movers @ ezmove.in/packers-and-movers-chennai.html

By Swati Kumari on   07 September 2015 04:17
Gravatar

Packers & Movers

The article is fantastic.I enjoyed alot while reading. Thanks for sharing a valubale information with us.
movers and packers in delhi @ ezmove.in/packers-and-movers-delhi.html
packers and movers in navi mumbai @ ezmove.in/packers-and-movers-mumbai.html
movers and packers in mumbai @ ezmove.in/packers-and-movers-mumbai.html
movers and packers in pune @ ezmove.in/packers-and-movers-pune.html
movers and packers in hyderabad @ ezmove.in/packers-and-movers-hyderabad.html
packers and movers in bangalore @ ezmove.in/packers-and-movers-bangalore.html
chennai packers and movers @ ezmove.in/packers-and-movers-chennai.html

By Swati Kumari on   07 September 2015 04:18

Cheap Air Max 90 UK

sometimes you happen to be communicate with your file transfer protocol blog or machine which included a account name and in addition code. notwithstanding, "private file transfer protocol staff" be able to login similar to a invitees without any subsequent operator phrase and merely your individual e mail street address due to private data. thus giving you ability to access the file types that had been put in the publicly available a component the file transfer protocol world wide web site.
# Cheap Air Max 90 UK

By TrackBack on   07 September 2015 23:01
Gravatar

Packers and Movers India

Thanks for Nice and Informative Post. This article is really contains lot more information about This Topic. -
Packers and Movers Chennai
Packers and Movers Hyderabad
Packers and Movers Mumbai
Packers and Movers Noida

By Akash Sharma on   05 October 2015 01:24
Gravatar

Packers and Movers India

This article is really fantastic and thanks for sharing the valuable post.
Packers and Movers Pune
Packers and Movers Bangalore
Packers and Movers Delhi
Packers and Movers Gurgaon

By Akash Sharma on   05 October 2015 01:28
Gravatar

Packers and Movers India


Thanks for sharing your info. I really appreciate your efforts and I will be waiting for your further write
Packers and Movers Faridabad
Packers and Movers Thane
Packers and Movers Navi Mumbai
Packers and Movers Ghaziabad

By Akash Sharma on   05 October 2015 01:28
Gravatar

Packers and Movers India

Thanks for post this helpful post - Please visit for More information about -
Packers and Movers Gurgaon
Packers and Movers Bangalore
Packers and Movers Hyderabad
Packers and Movers Pune

By Akash Sharma on   05 October 2015 01:29

weblink

Fantastic Website, Stick to the useful work. Thank you so much.
# weblink

By TrackBack on   05 October 2015 21:18

click site

Awesome Webpage, Stick to the great job. thnx!
# click site

By TrackBack on   10 October 2015 07:52

my review here

Fantastic Web-site, Continue the useful job. With thanks.
# my review here

By TrackBack on   16 October 2015 12:43

garage door openers

Superb Webpage, Carry on the excellent work. Regards.
# garage door openers

By TrackBack on   18 October 2015 14:00
Gravatar

Packers and Movers in Kolkata @ http://www.packersmove.com/packers-and-movers-kolkata.php

Packers and Movers in Gurgaon @ www.packersmove.com/packers-and-movers-gurgaon.php. It is one of the exercises through which one needs to assemble all the Packers and Movers in Ghaziabad @ www.packersmove.com/packers-and-movers-ghaziabad.php pressing materials to begin the pressing work of movement assignment. In the wake of pressing the unsafe work moving is left on the shoulders of shifters. Packers and Movers in Kolkata [http://www.packersmove.com/packers-and-movers-kolkata.php].

By Raghav Singh on   20 October 2015 05:07
Gravatar

Packers and Movers India

Packers and Movers Hyderabad
Packers and Movers Delhi
Packers and Movers Pune
Packers and Movers Gurgaon

By Boom Shankar on   17 March 2016 07:51
Gravatar

Packers and Movers India


Packers and Movers Pune
Packers and Movers Bangalore
Packers and Movers Gurgaon
Packers and Movers Mumbai

By Boom Shankar on   17 March 2016 07:52
Gravatar

Packers and Movers in hyderabad


To get best Packing and Moving facility in Hyderabd visit:
www.movers5th.in/packers-and-movers-hyderabad/
To get best Packing and Moving facility in Bangalore visit:
www.movers5th.in/packers-and-movers-bangalore/
To get best Packing and Moving facility in Pune visit:
www.movers5th.in/packers-and-movers-pune/

By Packers and Movers in Hyderabad on   11 April 2016 04:21
Gravatar

Packers and Movers in Mumbai


To get best Packing and Moving facility in Mumbai visit:
www.movers5th.in/packers-and-movers-mumbai/
To get best Packing and Moving facility in Delhi visit:
www.movers5th.in/packers-and-movers-delhi/
To get best Packing and Moving facility in Gurgaon visit:
www.movers5th.in/packers-and-movers-gurgaon/

By Packers and Movers in Mumbai on   11 April 2016 04:22
Gravatar

Packers and Movers in Chennai

To get best Packing and Moving facility in Chennai visit:
www.movers5th.in/packers-and-movers-chennai/
To get best Packing and Moving facility in Noida visit:
www.movers5th.in/packers-and-movers-noida/
To get best Packing and Moving facility in Navi mumbai visit:
www.movers5th.in/packers-and-movers-navimumbai/
To get best Packing and Moving facility in Thane visit:
www.movers5th.in/packers-and-movers-thane/
To get best Packing and Moving facility in Ghaziabad visit:
www.movers5th.in/packers-and-movers-ghaziabad/
To get best Packing and Moving facility in Faridabad visit:
www.movers5th.in/packers-and-movers-faridabad/

By Packers and Movers in Chennai on   11 April 2016 04:22
Gravatar

Packers and Movers in Pune

To get best Packing and Moving facility in Pune visit:
www.moveby5th.in/packers-and-movers-pune.html
To get best Packing and Moving facility in Bangalore visit:
www.moveby5th.in/packers-and-movers-bangalore.html
To get best Packing and Moving facility in Hyderabad visit:
www.moveby5th.in/packers-and-movers-hyderabad.html
To get best Packing and Moving facility in Mumbai visit:
www.moveby5th.in/packers-and-movers-mumbai.html
To get best Packing and Moving facility in Gurgaon visit:
www.moveby5th.in/packers-and-movers-gurgaon.html
To get best Packing and Moving facility in Delhi visit:
www.moveby5th.in/packers-and-movers-delhi.html

By Packers and Movers in Pune on   11 April 2016 04:23
Gravatar

http://www.michael-korsoutletonline.us.com

Miranda Kerr Has Perfectly Simple Supermodel Shoe Style
www.giuseppezanotti.us.org Women Giuseppe Zanotti Sneakers - giuseppe zanotti shoes
My love for handbags started at a young age, and it began with lusting, not owning. I used to go to the mall with my friends in junior high, and while they were in Limited Too, I was in department stores, looking at bags.
www.coachfactoryoutlet.org Coach Outlet - Hot Deals, Reviews and Guides about Coach Produtcs 2016
michael kors outlet so yes, www.michael-korsoutletonline.us.com first www.coachfactoryoutletonlineco.us.com order www.oakleysunglassesok.us.com of business: www.oakleysunglassesoutlets.us.org we've got www.raybansunglasses.eu.com a lot www.ralphlaurenpolos.us.com of www.michaelkorsoutlet.us.com Rihanna www.coach-factoryoutletstore.us.com for www.louis-vuittonoutletonline.us.com you www.michaelkorsoutletonline.us.com this www.valentinoshoesoutlet.com week, and www.valentinooutlet.us.org in one www.sacsportefeuilles.com instance,www.louisvuittonhandbag.org she is www.oakleysunglassesstore.us.com actually www.coachoutletstore.us.com carrying www.coachfactoryoutletinc.us.com something www.coachfactoryoutletusa.com other www.michaelkorsoutletonlines.us.com than Dior.http://www.michaelkorsoutletinc.us.com (Nobody www.michael-korsoutletonline.com tell www.michaelkorsoutlet.eu.com Dior's PR www.michaelkorsfactoryoutletonline.us.com department.http://www.oakleyoutlet.name oakley outlet) Is www.oakleystoresonline.us.com there www.truereligionoutletonline.in.net any www.marcbymarcjacobs.us.org

coach factory outlet www.coachfactoryoutlet-stores.us.com selling www.sacportefeuillespascher.com point than Rihanna? www.coach-factoryoutletstores.us.com No, www.michaelkorsfactorystore.us.com no there is www.north-faceoutlet.us.com not. www.coachfactoryoutlet-stores.com Second www.ray-banpascher.com order www.sacblanc.com of www.guccisneakers.us.com business: www.raybanstoresonline.us.com celebrities www.raybansunglassesclearance.com are www.coachoutletusaonline.us.com keeping www.tomsshoe.us.com it extra www.true-religions.us.com casual www.oakleygoggles.us.com this www.portefeuillepascher.com week. www.coachoutletonline.us coach outlet online www.valentino.com.co Sweatpants www.valentinoshoes.com.co at www.coachfactoryoutletstore.us.com the www.coachoutletstores.net airport.http://www.oakleyvaults.us.com Pajamas www.pradaoutletstore.us.com at www.michaelkorssoutlet.us.com award www.christianlouboutinsale.us.com show.http://www.valentinoshoeswebsite.com It www.christian-louboutinshoes.us.com makes www.beatsbydrdreheadphone.us.com Here's a photo of Dakota Fanning www.michaelkors-outletonline.us.com carrying www.michaelkorshandbagsoutlet.us.com a mini www.beatsbydreheadphone.us.com Givenchy www.louboutinshoes.us.com bag around www.christianlouboutinoutletonline.us.com the www.coachstores.us.com East www.coachoutletonlinesale.us.com Village.

michael kors www.onlinemichaelkorsoutlet.us.com Someone www.truereligionoutlet.us.com clearly took this www.coachoutletstorefactory.us.com on www.ray-bansunglasses.it their www.cheapsunglassesoakley.us.com cell www.coach-factorystoreonline.us.com phone and www.michaelkorsoutletco.us.com sold to our www.tomsshoesoutletonline.in.net photo www.truereligionoutletco.us.com service. www.truereligionjeans.us.org Dakota sees www.raybansunglasses.uk.com you www.redbottomshoe.us.com trying to take discreet hip www.valentinorockstudshoes.us.com shots www.valentinoshoesoutlet.us.com with www.sacenpaille.com your www.beatsbydrdre.us.com smart phone,www.ray-bansunglasses.org ray ban sunglasses aspiring www.louboutinoutlet.us.com paparazzo,www.modeldesac.com and does not www.clshoesoutletonline.com approve. www.raybanoutletstoreonline.com I www.tomsoutlet.us.com wear a www.louboutinshoes.us.com lot of www.christianlouboutinoutlet.us.com black, www.hermesbirkinoutlet.us.com dye www.hermesbag.us.com my hair www.wwwcoachoutlet.us.com bright www.coachfactory.name colors www.raybansunglasse.us.com and www.coachoutletstoresfactory.com coach factory outlet sale don't own a www.bracelethermes.com single www.factorystoreonline.com fashion-related www.coachpurses.us.com thing www.outletgucci.us.com that www.coachfactory-storeoutlet.us.com would www.valentinoshoes.us.org qualify www.louisvuittonoutlet-online.us.com as www.louisvuittonlv.us.com even www.michaelkorsoutletsite.us.com vaguely www.michaelkorshandbags.us.com pastel, www.valentinorockstud.us.com but www.louisvuittonpurses.us.com somehow

louis vuitton www.bananelouisvuitton.com they're www.oakleysunglasse.us.com the only www.pascherhermes.com shades that feel www.womens-jewelry.com consistently coright on www.valentinooutlet.org my www.valentinoshoes.us.com nails. www.oakleyssunglassesoutlet.us.com Even www.ray-bansunglassesclearance.com black, www.raybangoggles.us.com my www.raybanstoreonline.us.com favorite www.raybansunglassesoutlets.com color www.cheapoakleyssunglasses.us.com for www.cheapoakleysunglasses.com.co everything www.tomsoutlet.in.net else www.abercrombieoutletonline.us.com I put on my www.ralphlauren-outlet.us.com body, doesn't www.poloralphlaurenoutlet.us.com fit www.raybansoutlet.us.com all www.coach-factorystoreoutlet.us.com the www.wwwcoachfactoryoutlet.com time, www.coach-factorystore.us.com but www.coach-factoryonline.us.com I've www.coach-outletfactoryonline.us.com never had a www.outlet-michaelkors.us.com baby www.raybanssunglasses.us.com blue www.polosralphlauren.us.com or www.sacportefeuilleeu.com mint www.marcjacobsoutlet.us.org green manicure I've regretted.http://www.marcbymarcjacobs.us Pale nails have been an outlier in my life for years.
www.marcbymarcjacobsoutlets.com
www.chiflatironsofficial.com

Katherine Callaghan
6546 Comments

Well, we’ve made it. Here’s to another week marked off our calendar and another fun-filled weekend to look forward to. While the sales were scarce this week, we searched the internet high and low to bring you the best-priced bags we could find.

By Michael Kors Outlet Online on   27 April 2016 01:46
Gravatar

Hassle-Free Packers and Movers




Packers and Movers in Gurgaon go to:-
www.moveby5th.in/packers-and-movers-gurgaon.html
Packers and Movers in Pune go to:-
www.moveby5th.in/packers-and-movers-pune.html
Packers and Movers in Bangalore go to:-
www.moveby5th.in/packers-and-movers-bangalore.html
Packers and Movers in Hyderabad go to:-
www.moveby5th.in/packers-and-movers-hyderabad.html

By Deepak Jha on   02 May 2016 07:12
Gravatar

Re: IMPLIED OBLIGATIONS AND TIMELY CONTRACT TIME EXTENSIONS & CHANGE ORDERS

Packers and Movers Gurgaon go to:-
www.movers5th.in/packers-and-movers-gurgaon/
Packers and Movers in Delhi go to:-
www.movers5th.in/packers-and-movers-delhi/
Packers and Movers Mumbai go to:-
www.movers5th.in/packers-and-movers-mumbai/

By Deepak Jha on   02 May 2016 07:12
Gravatar

Hassle-Free Packers and Movers

Packers and Movers Hyderabad go to:-
www.movers5th.in/packers-and-movers-hyderabad/
Packers and Movers Pune go to:-
www.movers5th.in/packers-and-movers-pune/
Packers and Movers Bangalore go to:-
www.movers5th.in/packers-and-movers-bangalore/

By Deepak Jha on   02 May 2016 07:14
Gravatar

Re: IMPLIED OBLIGATIONS AND TIMELY CONTRACT TIME EXTENSIONS & CHANGE ORDERS

curry shoes www.curry-shoes-sale.us
stephen curry shoes www.curry-shoes-sale.us
curry shoes one www.curry-shoes-sale.us
curry shoes two www.curry-shoes-sale.us
kevin durant shoes www.curry-shoes-sale.us
lebron james shoes www.curry-shoes-sale.us
kobe bryant shoes www.curry-shoes-sale.us

Stephen Curry Jersey www.curryjersey.com
Cheap Curry Jersey www.curryjersey.com
Curry Jersey sale www.curryjersey.com
lebron james jersey www.curryjersey.com
kobe bryant jersey www.curryjersey.com
kevin durant jersey www.curryjersey.com
Cheap Curry jersey www.curryjersey.com
kids curry jersey www.curryjersey.com


Stephen Curry Jersey www.curryjersey.com
Stephen Curry Shoes www.curryjersey.com
Curry Shoes One www.curryjersey.com
Curry Shoes Two www.curryjersey.com
Curry Shoes www.curryjersey.com
UA Clutchfit Drive www.curryjersey.com
Kids Curry Jersey www.curryjersey.com
[url=http://www.curry-shoes-sale.us] curry shoes[/url]
[url=http://www.curry-shoes-sale.us] stephen curry shoes[/url]
[url=http://www.curry-shoes-sale.us] curry shoes one[/url]
[url=http://www.curry-shoes-sale.us] curry shoes two[/url]
[url=http://www.curry-shoes-sale.us] kevin durant shoes[/url]
[url=http://www.curry-shoes-sale.us] lebron james shoes[/url]
[url=http://www.curry-shoes-sale.us] kobe bryant shoes[/url]

[url=http://www.curryjersey.com] Stephen Curry Jersey[/url]
[url=http://www.curryjersey.com] Cheap Curry Jersey[/url]
[url=http://www.curryjersey.com] Curry Jersey sale[/url]
[url=http://www.curryjersey.com] lebron james jersey[/url]
[url=http://www.curryjersey.com] kobe bryant jersey[/url]
[url=http://www.curryjersey.com] kevin durant jersey[/url]
[url=http://www.curryjersey.com] Cheap Curry jersey[/url]
[url=http://www.curryjersey.com] kids curry jersey[/url]


[url=http://www.curryjersey.us] Stephen Curry Jersey[/url]
[url=http://www.curryjersey.us] Stephen Curry Shoes[/url]
[url=http://www.curryjersey.us] Curry Shoes One[/url]
[url=http://www.curryjersey.us] Curry Shoes Two[/url]
[url=http://www.curryjersey.us] Curry Shoes[/url]
[url=http://www.curryjersey.us] UA Clutchfit Drive[/url]
[url=http://www.curryjersey.us] Kids Curry Jersey[/url]

By stephen curry shoes on   13 June 2016 10:39
Gravatar

Re: Use A Level Of Effort To Add Work Stoppage Info To A Project and Still Track To Your Primavera Baseline

armani exchange
red bottoms outlet online
birkenstocks
levis 511
coach factory outlet online
versace sunglasses wholesale
michael kors outlet
canada goose jackets
nhl jerseys wholesale
burberry outlet
ray ban outlet
sac longchamp pliage
air max
coach outlet online
adidas nmd black
canada goose outlet
ralph lauren outlet
rolex submariner
birkenstock outlet
longchamp uk
burberry outlet
louis vuitton outlet online
adidas pure boost black
new balance shoes
coach outlet online
polo ralph lauren men
ray ban outlet store
michael kors handbags
converse outlet
michael kors outlet online
true religion jeans
oakley sunglasses outlet
adidas shoes
nike free flyknit 3.0
ghd hair dryer
omega
skechers outlet
north face uk
adidas superstars
nike huarache black
ray ban sunglasses outlet
adidas superstar white
ray ban sunglasses outlet
nike cortez white
the north face outlet
cheap ray-ban sunglasses outlet
coach outlet online
north face outlet
cheap ray bans
cartier love ring
gucci handbags outlet
reebok classic
michael kors outlet store
rolex watches for sale
nike roshe run
polo ralph lauren
louis vuitton uk
oakley sunglasses
ed hardy
michael kors outlet online
tiffany jewelry
nike shoes for cheap
supra store
white converse
kate spade uk
michael kors outlet online
cheap oakleys
nike free flyknit 3.0
louis vuitton handbags
polo ralph lauren outlet
true religion jeans outlet
true religion uk
michael kors outlet clearance
reebok
coach purses on sale
oakley sunglasses,oakley sunglass,cheap oakley sunglasses,oakley sunglasses cheap,oakley sunglasses outlet,oakley store,oakley outlet,oakley outlet store,oakley sunglasses sale,oakley sunglasses discount
timberland boots outlet
lacoste polo shirts
mizuno running shoes
ralph lauren uk
louis vuitton pas cher
burberry outlet stores
christian louboutin outlet
tiffany jewelry outlet
rolex replica watches
yeezy boost
cheap oakleys
kate spade handbags
coach factory outlet
nike air force
yeezy boost 350
chaussure louboutin
cheap oakley sunglasses
cheap ray ban sunglasses
ghd
michael kors outlet canada
ralph lauren outlet
stan smith adidas
adidas shoes
true religion outlet
coach factory outlet
coach outlet online
michael kors outlet
louis vuitton outlet online
gucci borse
louboutin outlet
prada handbags
north face jackets
oakley sunglasses wholesale
vans store
jimmy choo
toms outlet
air max 90
ray ban sunglass,ray ban sunglasses,ray ban outlet,cheap ray bans,cheap ray ban sunglasses,cheap ray bans,ray bans
asics gel kayano
hollister clothing
mlb jerseys wholesale
vans outlet store
ray ban sunglasses
true religion
jordan shoes
hermes belt
christian louboutin shoes
micahel kors
louboutin shoes
cheap ray bans
air max 90 white
true religion sale
coach factory outlet
timberland shoes
ray bans
babyliss hair dryer
kate spade outlet
coach factory outlet
ralph lauren
lacoste shoes
coach outlet online
pandora jewelry
kobe bryant shoes
gucci outlet online
air jordan shoes
nike tn pas cher
oakley sunglasses uk
oakley sunglasses outlet
mont blanc pens outlet
michael kors outlet online
longchamp outlet
nike free runs
true religion outlet store
fitflops sale clearance
jordans
kate spade outlet
birkenstocks
nike air max 95
ray ban outlet store online
tiffany uk
valentino bags
jimmy choo outlet store
stephen curry basketball shoes
coach factory outlet online
birkenstock shoes
coach outlet online
asics running shoes
versace sunglasses
michael kors handbags outlet
coach factory outlet online
coach factory outlet online
louis vuitton outlet
ray-ban sunglasses outlet
white converse
michael kors canada
hollister kids
louis vuitton handbags
cheap ray ban sunglasses
armani outlet
air max 90
omega speedmaster
yeezy boost 350 balck
nike air force black
ugg boots
michael kors canada
polo ralph lauren
pandora charms
hollister uk
nike free 5.0
louboutin pas cher
adidas nmd uk
polo ralph lauren outlet
louis vuitton purse
nike flyknit racer
pandora charms uk
true religion jeans
polo ralph lauren
kate spade handbags
supra outlet
michael kors outlet online
discount oakley sunglasses
designer handbags wholesale
cheap oakley sunglasses outlet
cheap oakley sunglasses
nike air max 90
reebok outlet store
coach factory outlet
coach outlet online
coach factory outlet
ray bans
nba jerseys wholesale
michael kors purses
coach outlet store online clearance
michael kors bags
black timberland boots
nike blazer
cheap ray bans
hollister clothing store
kobe 11
under armour
nmd adidas
cartier
louboutin shoes
ralph lauren pas cher
tory burch outlet online
coach outlet store
michael kors outlet online
louis vuitton bags
ed hardy uk
puma outlet
cheap jordan shoes
nike trainers
birkenstock uk
cheap nike air max
prada sunglasses wholesale
buy red bottoms
fitflops shoes
ray bans
michael kors outlet
adidas nmd runner
michael kors outlet online
michael kors bags
louis vuitton outlet
nike huarache
louis vuitton handbags
reebok shoes
sac longchamp
bottega veneta sale
louis vuitton borse
cheap nfl jerseys
hermes outlet
cheap jordan shoes
louis vuitton outlet online
under armour outlet store
rolex daytona
fitflops
polo ralph lauren outlet online
michael kors handbags
oakley sunglasses outlet
burberry outlet canada
abercrombie outlet
nike free flyknit 5.0
cheap basketball shoes
ugg boots
toms outlet store
bottega veneta shoes
christian louboutin outlet
lebron james shoes 2016
cheap jordans
dior sunglasses 2016
cheap jordan shoes
adidas supercolor pink
ferragamo outlet
nike free run flyknit
michael kors outlet
toms outlet
kate spade bags
valentino
fake oakleys
michael kors uk
ferragamo
discount nike air max
converse sale
adidas trainers
fitflops sale clearance
ecco outlet
adidas gazelle
nike air max 90
nike store uk
coach outlet store
michael kors outlet clearance
hollister clothing store
wholesale nike shoes
polo ralph lauren outlet
michael kors uk
fitflops shoes
christian louboutin uk
yeezy boost 750
jordan pas cher
tiffany and co outlet
yeezy boost 350 white
fitflops
louis vuitton purse
timberland uk
pandora jewelry outlet
chi flat iron
nike force 1
instyler max
abercrombie & fitch
nike cortez shoes
nike running shoes
michael kors outlet stores
cheap nfl jerseys
oakley sunglasses cheap
chenzhen2016620

By chenzhen2016620 on   20 June 2016 01:47

cheap oakley glasses

It is nоt a very clear time that moncler italia, in france they classical jacket brand, hаs conquered a lot of stars suddenly, аѕ thеir necessity garments іn winter. Maybe this brand Moncler is not familiar by everybody. Additionally јust knew it lately. It was built by three Frenchmen fifty years ago. It іs very popular іn European us. It belongs tо thе ѕаme level wіth LV, GUCCI and PARDA brands. So іts costs are worth sеverаl dollars leastwise. That decides іts consumption groups аre wealthy stars and businessmen, whіle ordinary people can't afford it whatsoever. While today, I can be сertаіn inform you, you could have each fashion Moncler Earth friendly. Moncler Clothing уou like, simply with the lowest price. Select longer might nоt be.
# cheap oakley glasses

By TrackBack on   27 June 2016 18:09
Gravatar

Re: IMPLIED OBLIGATIONS AND TIMELY CONTRACT TIME EXTENSIONS & CHANGE ORDERS

nike air force, ugg boots uk, new balance shoes, hermes belt, mont blanc, lancel pas cher, nike roshe run, oakleysunglasses1.us.com, tiffany and co, louboutin outlet, marc jacobs, herve leger, michael kors outlet canada, michael kors, michael kors outlet, moncler outlet, moncler, polo outlet, burberry factory outlet, canada goose outlet, hermes birkin, longchamp outlet, louboutin shoes, links of london, chaussures louboutin, moncler, true religion outlet, oakley sunglasses cheap, pandora charms, air max, michael kors outlet online, uggs outlet, louboutin, ghd hair straighteners, ralph lauren, michael kors bags, true religion jeans, air max 2015, moncler outlet, ray ban pas cher, cheap nike shoes, gucci belts, rolex watches for sale, lululemon, replica watches, vans pas cher, tiffany jewelry, moncler uk, nike trainers, longchamp pliage, sac guess, supra shoes, oakley vault, nfl jerseys, nike free run, sac longchamp, cheap ugg boots, north face uk, oakley sunglasses outlet, air jordan pas cher, christian louboutin, michael kors handbags, bottega veneta, discount oakley sunglasses, celine bags, vans shoes, swarovski jewelry, nike free run uk, jordan 12, ralph lauren outlet, karen millen, converse, montre homme, coach outlet online, nike free pas cher, north face outlet, louboutin shoes, uggs, oakley store, longchamp bags, converse shoes, mulberry uk, ralph lauren outlet, oakley sunglasses cheap, swarovski, michael kors outlet online, michael kors handbags, wedding dresses, christian louboutin, replica handbags, true religion jeans, true religion outlet, louis vuitton purses, ugg boots clearance, scarpe hogan, the north face, lululemon, hogan outlet, longchamp outlet online, sac longchamp pas cher, new balance, canada goose jackets, north face jackets, jordan 4, ray ban sunglasses outlet, pandora jewelry, nike free, sac louis vuitton, moncler, cheap ugg boots outlet, michael kors, moncler outlet, vans, nike outlet store, polo ralph lauren outlet online, louis vuitton outlet online, michael kors outlet, christian louboutin, michael kors outlet, abercrombie, sac hermes, true religion outlet, louis vuitton handbags, louis vuitton, swarovski crystal, longchamp bags, nike free run pas cher, hollister canada, longchamp outlet online, vans scarpe, hollister, montre femme, jordan 1, louis vuitton, bottes ugg pas cher, retro jordans, hollister, ugg australia, bottes ugg, air huarache, thomas sabo uk, new jordans, jordan xx9, moncler jackets, karen millen uk, ugg boots, ray ban outlet, chi flat iron, rolex watches, canada goose, hollister, air max, uggs on sale, hollister, moncler jackets, michael jordan shoes, longchamp, hollister, tory burch, pandora jewelry, nike tn pas cher, christian louboutin outlet, moncler sito ufficiale, ugg outlet, canada goose, celine handbags, oakley pas cher, burberry handbags, louis vuitton outlet, ugg outlet, burberry outlet online, nike air max pas cher, nike blazer, cheap oakley sunglasses, michael kors, longchamp, ugg boots, converse pas cher, louis vuitton handbags, north face jackets, michael kors outlet, burberry, roshe run pas cher, louis vuitton outlet stores, swarovski uk, beats headphones, air jordan, moncler, sac burberry, wedding dress, tiffany jewelry, air jordan shoes, kate spade outlet online, burberry outlet, mcm handbags, oakley, lunette ray ban pas cher, true religion jeans, canada goose outlet, tn pas cher, doudoune canada goose, michael kors outlet online sale, coach bags, nike air max, doudoune moncler, gucci handbags, uggs, phone cases, vanessa bruno pas cher, oakley glasses, michael kors outlet, replica watches uk, lunette oakley pas cher, ralph lauren, jordan 6, sac lancel, montre pas cher, ugg boots, reebok outlet, reebok shoes, ralph lauren outlet online, nike free run, michael kors outlet, air force, longchamp pas cher, hogan sito ufficiale, nike trainers uk, http://www.michael-korsoutletonline.eu.com/, nike free, baseball bats, thomas sabo, michael kors outlet online, uggs, nike factory outlet, abercrombie and fitch uk, abercrombie, the north face, uggs, louis vuitton, michael-korsoutletonline.eu.com, nike roshe, burberry outlet, cheap oakley, michael kors outlet online, michael kors canada, jordan 3, nike roshe run pas cher, michael kors, michael kors outlet online sale, louis vuitton, nike tn, longchamp, juicy couture, moncler, uggs, canada goose, canada goose pas cher, michael kors, jordan 11, abercrombie, jordan future, red bottom shoes, christian louboutin uk, abercrombie and fitch, michael kors, michael kors, chanel handbags, louboutin, christian louboutin,